Last updated: 05/08/2026

Welcome to CDS Electrical Solutions. These Terms & Conditions govern your use of cdselectricalsolutions.co.uk and the services we provide. By accessing our website or engaging our services, you agree to be bound by these Terms & Conditions.

1. About Us

CDS Electrical Solutions provides professional electrical engineering services, including electrical infrastructure, commercial installations, containment systems, power distribution, inspection and testing, electrical maintenance, automatic barrier systems, engineering design and project delivery throughout the United Kingdom.

2. Use of Our Website

You agree to use this website lawfully and not to:

• Attempt to gain unauthorised access to our systems.
• Introduce malicious software, viruses or harmful code.
• Copy, reproduce or distribute website content without our written permission.
• Use our website in any way that may disrupt its operation or security.

We reserve the right to suspend or restrict access where misuse is identified.

3. Quotations

All quotations are provided free of charge unless otherwise stated.

Unless specified otherwise, quotations remain valid for 30 days from the date issued. Quotations are based upon the information available at the time and may be revised if project specifications, site conditions or client requirements change.

4. Orders and Acceptance

A contract is formed once a quotation has been accepted in writing or by email and confirmed by CDS Electrical Solutions.

Any variations requested after acceptance may affect pricing, programme dates and completion times.

5. Payment Terms

Payment terms will be detailed within each quotation or contract.

Unless otherwise agreed:

• Invoices must be paid within the agreed payment period.
• Late payments may incur interest in accordance with the Late Payment of Commercial Debts (Interest) Act 1998.
• We reserve the right to suspend work where payments become overdue.

6. Project Delivery

We aim to complete all projects within agreed timescales.

However, completion dates are estimates and may be affected by circumstances outside our reasonable control, including:

• Client-requested changes
• Delays in obtaining materials
• Restricted site access
• Weather conditions
• Third-party contractors
• Unforeseen technical issues

We will always endeavour to minimise delays and keep clients informed throughout the project.

7. Client Responsibilities

Clients agree to:

• Provide accurate project information.
• Ensure safe and reasonable access to the site.
• Obtain any permissions required before work begins.
• Inform us of any known hazards or restrictions affecting the work.

Delays caused by incomplete information or restricted access may affect project costs and timescales.

8. Warranties

We take pride in delivering work to the highest professional standards.

Manufacturer warranties remain subject to each manufacturer’s own terms and conditions.

Any workmanship guarantee offered by CDS Electrical Solutions will be detailed within the relevant quotation or contract documentation.

9. Limitation of Liability

To the fullest extent permitted by law, CDS Electrical Solutions shall not be liable for:

• Indirect or consequential losses.
• Loss of profit, revenue or business opportunities.
• Delays caused by circumstances beyond our reasonable control.

Nothing within these Terms excludes liability for death, personal injury, fraud or any liability that cannot legally be excluded.

10. Intellectual Property

All content published on this website, including text, graphics, logos, photographs and design, remains the property of CDS Electrical Solutions unless otherwise stated.

No content may be copied, reproduced or reused without prior written permission.

11. Links to Third-Party Websites

Our website may include links to external websites for your convenience.

We are not responsible for the content, availability or privacy practices of third-party websites.

12. Privacy

Your use of our website is also governed by our Privacy Policy, which explains how we collect, use and protect your personal information.

13. Changes to These Terms

We reserve the right to amend these Terms & Conditions at any time.

Any updates will be published on this page together with the revised “Last Updated” date.

14. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of England and Wales.

Any disputes arising from these Terms shall be subject to the exclusive jurisdiction of the courts of England and Wales.

Contact Us

If you have any questions regarding these Terms & Conditions, please contact:

CDS Electrical Solutions

Website: www.cdselectricalsolutions.co.uk

Email: info@cdselectricalsolutions.co.uk

Telephone: 01706 825738